ArticlePDF Available

How Can Procurement Create (Sustainable) Public Value under the Bipartisan Infrastructure Deal?

Authors:

Abstract and Figures

The economic response of the U.S. government to the COVID‐19 pandemic envisions massive investment in infrastructure construction. Yet, governments contract out public works and might lack the capacity to meet the increased demand for new construction. Drawing on a mix of survey and interview data, we identify critical deficiencies in contract capacity that might lead to a loss of public resources and further erode trust in the government. We propose a plan for restructuring public procurement systems and offer solutions around four foci: collaboration, training, flexibility, and sustainability. This transformation path would enhance government contract capacity and use markets to signal a demand for sustainable infrastructure and create public value in line with the strategic objectives of the Bipartisan Infrastructure Deal. This article is protected by copyright. All rights reserved.
Content may be subject to copyright.
How Can Procurement Create (Sustainable) Public Value under the
Bipartisan Infrastructure Deal?
Andrea S. Patrucco, Ph.D.
Assistant Professor of Supply Chain Management
Florida International University
College of Business
Department of Marketing and Logistics
Email: apatrucc@fiu.edu
Ana-Maria Dimand, Ph.D.
Assistant Professor of Public Policy and Administration
Boise State University
School of Public Service
Email: anamariadimand@boisestate.edu (corresponding author)
Milena I. Neshkova, Ph.D.
Associate Professor of Public Policy and Administration
Florida International University
Department of Public Policy and Administration,
Email: mneshnkov@fiu.edu
Madison M. Cevallos, JD
Government Affairs Specialist
Gordian
Email: M.Cevallos@gordian.com
Authors’ biographies
Andrea S. Patrucco, Ph.D. is an Assistant Professor of Supply Chain Management at FIU
Business. His research addresses the strategic management of procurement and buyer-supplier
relationships in the public and private sectors. He has published over 35 academic articles in
peer-reviewed journals in the supply chain and public management fields, and he actively
collaborates with private companies and public organizations in Europe and North America.
Ana-Maria Dimand, Ph.D. is an Assistant Professor of Public Policy and Administration in
the School of Public Service, at Boise State University. She holds a Ph.D. in Public Affairs and a
Graduate Certificate in Public Finance, Procurement, and Contract Management, from Florida
International University, Miami. Her research focuses on public management, government
contracting, environmental policy, sustainability, innovation, and collaborative governance.
Milena I. Neshkova, Ph.D. is an Associate Professor of Public Policy and Administration in the
Green School of International and Public Affairs at Florida International University. Her
This article has been accepted for publication and undergone full peer review but has not been
through the copyediting, typesetting, pagination and proofreading process which may lead to
differences between this version and the Version of Record. Please cite this article as doi:
10.1111/puar.13575
This article is protected by copyright. All rights reserved.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
research interests include public management, comparative and international public
administration, collaborative governance, and managing public money.
Madison M. Cevallos, J.D. is a Government Affairs Specialist with experience in legislative,
legal, and rule of law analysis. She has a B.A. in International Affairs from The George
Washington University, concentrating in Security Policy, and J.D. from the University of South
Carolina School of Law. Madison Cevallos is member of the South Carolina Bar.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
How Can Procurement Create (Sustainable) Public Value under the
Bipartisan Infrastructure Deal?
Abstract
The economic response of the U.S. government to the COVID-19 pandemic envisions massive
investment in infrastructure construction. Yet, governments contract out public works and might
lack the capacity to meet the increased demand for new construction. Drawing on a mix of
survey and interview data, we identify critical deficiencies in contract capacity that might lead to
a loss of public resources and further erode trust in the government. We propose a plan for
restructuring public procurement systems and offer solutions around four foci: collaboration,
training, flexibility, and sustainability. This transformation path would enhance government
contract capacity and use markets to signal a demand for sustainable infrastructure and create
public value in line with the strategic objectives of the Bipartisan Infrastructure Deal.
Keywords: Contract capacity; infrastructure construction; public procurement; contract
management
Acknowledgments: The authors would like to thank Lauren Fields (Director, Brand and
Marketing Communications), Randy Horn (Director, Business Development, Western Region),
Tom Brewer (Content Manager), Blaire Collins (Creative Manager), Pete Jutras (Visual
Production Specialist), Liz Rubel (Corporate Marketing Specialist) at Gordian, and Todd Slater
(Chief Content Officer) at NIGP, for their invaluable support and suggestions throughout the
research project.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Funding: This research was sponsored by Gordian and NIGP: The Institute for Public
Procurement, who partnered in 2021-2022 to fund market research on construction project
delivery method challenges and opportunities.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Evidence for Practice
The Bipartisan Infrastructure Deal (BID) of 2021 appropriates billions of dollars to
rebuild the nation’s aging infrastructure and is a potential game-changer for the U.S.
economy.
Governments rely on contractors for public works, and the increased demand might strain
existing local, state, and federal procurement systems. The lack of contract capacity can
result in poor project execution, a waste of public money, corruption, and erosion of trust.
The weaknesses of current contract management are rooted in the shortage of qualified
procurement staff, thin quasi-markets for government goods and services, and scarce
market research on construction pricing.
Reimagining public procurement entails strengthening contract capacity by collaboration
with suppliers and using markets to create demand for environment-friendly and socially
responsible production of goods and services.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Introduction
In November 2021, the nation celebrated the passage of the Bipartisan Infrastructure Deal (BID),
a sweeping reform aiming to fix the nation’s aging infrastructure and jump-start the economy.
The bill appropriated $550 billion in new infrastructure spending for a total of $1.2 trillion in the
next five years to rebuild roads, bridges, and rails and improve telecommunication infrastructure.
Now that the celebration of bill passage is over, it is time for sobering questions.
Public organizations do not design and build infrastructure or other public works alone.
They foot the bill but contract the work to the private sector. This phenomenon has been referred
to as hybrid governmentbecause it takes the efforts of multiple parties across the sector lines
(Christiansen & Laegreid, 2011). Although the government has outsourced public works for
centuries, procurement and contract management have become increasingly complex. This is
especially true for infrastructure contracting, a laborious task requiring a professional capacity
that procurement systems might currently lack (Koppenjan & Enserink, 2009).
Scholars have long warned about inadequate government contract management and
project governance (e.g., Stanton, 2008; Joaquin & Greitens, 2012; Johnston, 2010; Kort &
Klijn, 2011). In a sense, the BID represents a double-edged sword. On the one hand, it is a
potential game-changer for the U.S. economy after the COVID-19 pandemic slowdown. The bill
can unprecedentedly improve the infrastructure after years of inadequate investments in roads,
rail, airports, ports, bridges, broadband connectivity lines, and water pipelines and create 800,000
new jobs by 2025 (Moody’s Analytics, 2021). On the other hand, public agencies currently face
procurement and contract management deficiencies coupled with labor supply shortages that
might preclude them from delivering on the BID’s objectives. The lack of organizational
capacity impacts the whole processfrom bidding to project execution and monitoring—and
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
can result in a waste of money, corruption, and a decline in public trust (Dimand, 2022). By
raising awareness about these imminent challenges, we seek to open a dialogue on how
governments could reform their procurement systems to maximize the BID benefits and create
sustainable public value.
The Construction Sector and the Economic Recovery from COVID-19
Before the COVID-19 pandemic, the U.S. economy was producing at unprecedented rates, with
quarterly Gross Domestic Product (GDP) growth of 2-3% and a marked increase in employment
and minimum wage (Center on Budget and Policy Priorities, 2022). More than any prior
economic recession, the pandemic affected specific industries (e.g., labor-intensive ones) while
leaving others relatively unscathed (e.g., those using information and virtual technologies). The
construction sector was severely hit (Maani & Galea, 2020), which generated significant adverse
effects for the economy (U.S. Bureau of Labor Statistics, 2021). Over the last 20 years,
construction in the U.S. contributed between 3.4% and 5% of GDP (U.S. Department of
Commerce, 2022), and the investment made by this industry has been closely linked to economic
growth (Nasir et al., 2014). While designating construction workers as essential has helped the
industry stay afloat, new post-pandemic challenges created a perfect storm throughout 2020 and
2021. On the supply side, social distancing restrictions, the impossibility of operating
construction sites at full capacity, short staffing due to shrinking labor markets, and raw
materials price increases, among others, limited the output of the sector and affected the
completion of large-scale projects (Alsharef et al., 2021; Love et al., 2021). On the demand side,
governments worldwide had to postpone infrastructure investments due to pandemic-related
budget shortfalls (Buckley, 2020). Because the public sector is the primary buyer for many
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
constriction companies, this further stalled the industry. In the U.S., public spending on
commercial construction projects plunged from $4.09 to $3.54 billion (-13.5%). Similar figures
are projected for 2022 (U.S. Census Bureau, 2022).
In the second part of 2021, the federal government rolled out several initiatives to refuel
the nation’s economy. As a result, agencies at all levels have commenced programs to support
new construction and bolster economic activity and employment. Some major initiatives include:
The U.S. Department of Transportation plans to invest $906 million in infrastructure
through the Infrastructure for Rebuilding America discretionary grant program. A total of
20 projects in 20 states will receive funding to improve highways, bridges, ports, and
railroads (U.S. Department of Transportation, 2022).
The Federal Aviation Administration is financing infrastructure improvements in 405
airports through more than $1.2 billion in airport safety and infrastructure grants
(Forconstructionpros.com, 2020).
Illinois has announced $39.5 million in new grants for 27 capital projects in underserved
communities across the state (Illinois Department of Commerce & Economic
Opportunity, 2020).
Arizona’s Pima County has approved $55 million to repair about 127 miles of local
roads, 45 miles of collector and arterials, and $165 million for local capital projects
(Demers, 2020).
The Port of Seattle Commission plans to proceed with about 20 projects worth
approximately $1.5 billion (Port Technology International Team, 2020).
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
The BID, passed in November 2021, represents the most significant recent infrastructure
reform. “Because of today’s vote, state and local officials will be able to invest in a more
efficient supply chain network. Ultimately, these new infrastructure investments will provide a
needed boost for the construction industry while making our economy more efficient” (AGC The
Construction Association, 2021). This statement by a construction official reflects the
enthusiasm about the new opportunities opened by the bill. The projected construction costs were
further increased after the bill’s passage, reaching over $2 trillion in 2025 (FMI, 2022).
The BID’s Potential for Value Creation
The BID covers a multitude of local, state, and nationwide projects, including roads and bridges,
public transit, freight, passenger rail, drinking, and wastewater infrastructure, ports, and airports
(The White House, 2021). It also allocates money forthe new economy,” such as broadband
deployment and adoption, grid security and resiliency, and clean energy. If appropriately
managed, the funding allocated through the bill can bring about a wave of construction projects
commissioned by governments at all levels and increase the quality and value of the delivered
projects. Below, we identify four potential BID benefits for the U.S. economy, informed by
current construction management and public administration research.
National development and new job creation. The construction industry delivers the
physical infrastructure that enables the functioning of other sectors. Infrastructure projects are
also highly labor-intensive and bring new jobs to the area (Heintz et al., 2009). The BID
envisions 700,000+ new jobs yearly in construction, manufacturing, and transportation (The
White House, 2021).
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Increased competition and project delivery quality. Governments have long struggled to
attract best-in-class suppliers, who find it more profitable to work with industrial buyers. Small
and medium companies are also severely underrepresented in government contracts. Such firms
often do not even compete for large public works considering their chances of being selected too
slim given the government’s focus on cost and price (Patrucco et al., 2021). Widely recognized
as a problem, the lack of competition in construction procurement can cause corruption in the
procurement process, mismanagement of funds, and poor project performance, including delays,
cost overrun, and low quality (Locatelli et al., 2017). Given its principles, structure, and size, the
BID could significantly stimulate government-supplier collaboration under the auspices of
public-private partnerships (Kort & Klijn, 2011) and attract a broader pool of companies to bid
for government contracts and even relocate for infrastructure projects. This, in turn, could result
in more competitive offers and a better quality of project delivery.
Growth in rural communities. Infrastructure projects spur local socioeconomic growth
(Pavel et al., 2018). Small and medium construction companies are more willing to tackle
projects in rural communities that satisfy basic infrastructure needs (e.g., healthcare and
educational facilities or transportation works). Such projects could induce the growth of local
small-medium businesses and boost regional economic development. The main objective of the
BID is to bring more projects to these traditionally neglected areas. Besides improving the
infrastructure, safety, and local economy, it will also stimulate more participation from small and
medium businesses.
Boost technological advancement. The construction sector holds a high technical
potential (Agarwal et al., 2016). Some companies have already adopted solutions for
productivity roadblocks and optimization gaps, but a large-scale adoption is yet to happen. As
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
the primary buyer of the industry, governments can encourage technology usage by introducing
ad-hoc contract incentives (McKinsey & Company, 2019). The BID represents the perfect
scenario to boost technological advancement and the diffusion of hardware technologies, such as
construction drones and trackers, that enhance productivity and security on project sites.
To produce these benefits, the BID requires that public organizations adopt new rules in
contracting out construction projects. First, per the Build America, Buy America Act, projects
funded with federal infrastructure assistance should use locally sourced iron, steel, construction
materials, and manufactured products. If contractors cannot source a project domestically,
procurement officials must carefully evaluate the possibility of awarding waivers. To qualify for
a waiver, contractors must demonstrate that local rules are “inconsistent with the public interest,
not available in sufficient and reasonably available quantities of satisfactory quality, and/or if
domestic products will increase the cost of the overall project by more than 25%.” Second, the
Make it in America Act adds new requirements to enhance transparency and accountability. One
example is a centralized website to publicize the requests and conceded waivers and facilitate
interaction between manufacturers and contractors (MadeinAmerica.com, n.d.; Alliance for
American Manufacturing, n.d.).
With its potential benefits and new rules for doing business, the reform will open a new
era for construction companies, but it will likely have a profound effect on the demand side as
well. The availability of infrastructure funding and new rules means that public organizations
must pull off significant “hybrid government” capabilities to procure, contract, and execute the
public works envisioned in the bill. In the end, materializing this “potential” value depends on
the government’s ability to make good decisions when contracting out infrastructure projects.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Deficiencies in Procurement and Contracting Capacity: Evidence from the
Field
The increased demand for construction projects, combined with the new requirements to buy
domestically and deliver on the BID strategic objectives, poses a fundamental question: Do
government procurement systems possess the capacity to face the new challenges?
We rely on quantitative and qualitative data collected from the field to answer this
question. Specifically, we surveyed U.S. officials tasked with procurement, construction, and
facility management in various types of public organizations. The collected data reveals the
magnitude of construction contracts and projects, delivery methods, transaction costs associated
with contract solicitation, and the challenges before contract and relationship governance.
Appendix A outlines the survey design, our data collection, and the results from 362 responses.
Semi-structured interviews with 30 public officers responsible for construction procurement in
their organizations complement the survey data. Appendix B depicts the interview process and
provides illustrative quotes. These data allow us to elaborate on the critical deficiencies public
procurement systems face in construction contracting. We distinguish between two types of
deficiencies—organization-wide and construction-specific. Figure 1 shows the groups split into
subthemes: managerial and knowledge deficiencies for the organization-wide one; and project
delivery methods and supplier evaluation deficiencies for the construction-specific one.
[FIGURE 1 ABOUT HERE]
As a methodological note to Figure 1, the flow structure follows Goia et al.’s (2013) data
analysis approach. Specifically, we differentiate among challenges (first-order concepts), issues
(second-order themes), and deficiencies (aggregate dimensions).
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Organizational Deficiencies
Many procurement officials consider procurement and contract management of their agencies
ineffective and indicate knowledge and capacity gaps preventing them from handling
construction projects efficiently and effectively. Respondents point to a lack of human capital to
design and monitor contracts and cope with administrative work. Having sufficient staff is
essential for managing complex projects. The issue of severe labor shortages is further amplified
by limited strategic planning for construction procurement:
“Our biggest headache [is] the lack of planning and the demand for
a quick turnaround on [project] jobs.” (Construction Manager,
State Government)
While planning is typically reserved for high-value projects (those above $0.5 million),
our data show that such projects represent a small portion of annual contracts (around 30%). This
implies that the remaining projects are, by and large, managed in an unstructured way.
There is no standardization, to look up stuff [previous
construction procurement procedures] in there...” (Superintendent
of Public Works, Local Government)
Interviewees agree that the desired timeline to procure construction projects is around
two months, though it can vary from project to project. Table 1 presents a different reality.
Procuring construction projects stretches beyond the intended timelines in over 75% of the cases,
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
sometimes leading to service delivery that no longer fits the needs. Regulatory controls (like the
Federal Acquisition Regulation) that seek to ensure compliance often introduce significant
delays. Extensive administrative work involved in contract design and management, coupled
with labor shortages, has caused further interruptions. As a result, pre-bidding and bidding
periods can last over a half year, slowing down projects potentially requiring urgent attention.
[TABLE 1 ABOUT HERE]
Our interviewees report missed opportunities for federal funding due to the inability to
compress the duration of the construction procurement process:
Given the constraints of funding through the Cares Act, the timing
was extremely tight. We started [the process] in October of last
year. By October 31st, we had gotten permits for three projects. The
funds were to terminate on December 31st. That left us two months
with various holidays to get these projects contracted. It was
extremely difficult managing that tight schedule, managing multiple
trades working simultaneously, [and] dealing with the shortage of
various materials. [All] that put us out until early February.
(Deputy Director of Public Works, County Government)
Problems also stem from the fragmentation of authority over contracting decisions for
construction projects. Procurement offices govern those decisions only in a few organizations1.
At the state level, for example, the Department of Transportation, Department of Management
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Services, Division of Real Estate, and Division of Facility Management can grant infrastructure
contracts, with the procurement office having only administrative or no involvement.
[Procurement] is not brought into the process early enough.
Department heads do not want to change [that].” (Purchasing
Manager, Local Government)
Such fragmented decision-making complicates contract management and oversight and
impedes process standardization.
It is frustrating the time it takes to get things done—bureaucratic
problems [and] going through far too many approval groups.
Routing the papers makes you want to pull your hair out.”
(Purchasing Manager, Local Government)
While departments might be more familiar with the context, and their input is invaluable
in designing contract solicitations, infrastructure procurement is an uphill task that requires
professional expertise and skills. Our data indicate that these qualities are not always present in
the procurement unit or other departments. To improve the value created through construction
procurement, interviewees emphasized the need for 1) a better understanding of the financial and
cost aspects of construction projects and contracts, 2) gathering supply market intelligence, and
3) developing expertise in bid evaluation.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
We are never sure they [procurement] are getting the best price.
We use our own historical knowledge to determine if the price
sounds reasonable. When getting three quotes, we simply compare
them to determine the market price.” (Director of Facility
Management, School District)
Construction Procurement Process Deficiencies
Our informants also identified deficiencies specific to the construction procurement process.
Figure 2 presents the most challenging and time-consuming issues, as seen by the survey
respondents. Evaluating suppliers’ bids, reaching an agreement about project specifications, and
gathering information on project progress are among the most pressing.
[FIGURE 2 ABOUT HERE]
The deficiencies combined with the massive procurement pace for construction projects,
the lack of strategic planning, and qualified staff have two significant implications. First, public
agencies will likely resort to more traditional and lengthy project delivery methods. One such
method is Design-Bid-Build (DBB), where each phase needs to end before the next begins.
Traditional delivery methods have been criticized for inefficiency and corruption (Messick,
2020). Only a third of our respondents indicate familiarity/use of alternative project delivery
methods, such as Indefinite Delivery Indefinite Quantity (IDIQ) or Job Order Contracting (JOC),
that allow for the completion of multiple projects through a single competitively awarded
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
contract. The reluctance of managers to leave their “comfort zone” seems to limit the application
of new approaches that could alleviate the issues associated with traditional delivery.
I have tried to push a JOC state bid project, but my higher-ups
would not allow it. I wanted to work with a company we worked
with in the past. Selfishly, it would have made it easier on my side. I
have not been able to push through a state contract for anything
bigger than $100k; I have always had to go through a bid process.
(Director of Parks and Recreation, Local Government)
Second, public organizations will likely struggle to secure the best price or award the best
supplier. Although federal regulations require that agencies ensure “fair and reasonable” prices
with contractors, our data show that competitive pricing is rarely achieved in thin markets. The
main reasons are the inability to 1) design competitive bids (based on reliable cost estimates) and
2) attract reliable suppliers for construction projects. That is why contracts are often awarded
noncompetitively:
The last project we bid on was a 9-acre pocket park. We had the
prebid meeting, and close to 10 people signed in from 10 different
places. In the long run, we only received two bids. We thought we
would get at least five to have a good idea of what we would deal
with. With only two, it turned out [the selected contractor] to be a
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
company that we had worked with in the past.” (Director, Parks and
Recreation, Local Government)
Solving the Procurement Capacity Challenge: Suggestions for System
Reimagine
Given the current procurement deficiencies, the BID offers an opportunity for reflection on how
to address them moving forward. Historically, outsourcing sought to solve the issues of
bureaucratic inefficiency and inject market mechanisms into the government’s provision of
goods and services. The goal has been to make the government more efficient. While important,
efficiency is not the only goal. The theory and years of experience have taught us that markets
produce efficient outcomes. However, research in public administration (e.g., Mackintosh, 1997;
Brunjes, 2022) once and again indicates that markets for government goods and services remain
incomplete, plagued with issues of limited competition, imperfect information, and preference
substitution between the priorities of government providers and consumer choices2. Important
questions now arise: How should we think about efficiency in the current era? What values
should be emphasized to enhance public service delivery? How can we leverage the efficiency of
markets to create and deliver public value? Below, we identify four critical foci (illustrated in
Figure 3) that could guide governments in system reimagining.
[FIGURE 3 ABOUT HERE]
Collaboration
Given what we know about markets for public goods, governments might achieve higher
efficiency by seeking collaboration rather than market competition. While competitive bidding
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
remains an integral part of the selection process, contract awards should be decided holistically.
Governments often contract with the same vendors for years and, as a result, know how to
achieve the best product from them.
Collaborative governance research offers ample evidence that cross-sectoral partnership
helps solve complex public problems (e.g., Kalesnikaite & Neshkova, 2021; Sørensen & Torfing,
2021). In the context of construction procurement, public organizations could explore the
potential of collaboration to increase the value of public service delivery. As our interviewees
note, collaborative approaches can strategically nurture their relationships with private and
nonprofit contractors and involve them early in the process—in contract solicitation and
design—to speed up the process. Governments could also join resources with other public
entities through, for example, cooperative purchasing. Only a few agencies in our sample (below
10%) use collaborative procurement for construction projects. Yet, those who do, prize it for
increasing coordination, allowing organizations to tap resources they do not possess, expanding
social capital, improving conflict and risk management, and boosting compliance with local and
national regulations (Douglas & Ansell, 2021).
When we piggyback on contracts done through other agencies,
there is less effort…somebody else did the procurement work; we
just need to customize what already exists. It is very efficient, and
once it is underway, it is easier to control and monitor projects.”
(Purchasing Manager, School District)
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Increasing the use of alternative project delivery methods can also enhance collaboration.
While, traditionally, public organizations have collaborated with suppliers using variations of
DBB (e.g., through public-private partnership schemes3), the BID presents an opportunity to
explore collaborating through other methods. One example is JOC which builds on performance-
based contracting to incentivize local suppliers and delivery quality (Patrucco & Dimand, 2021).
While underutilized (87 survey respondents and six interviewees use it for procuring
construction projects), JOC promises public entities more effective governance of contractor
relationships, better communication, less opportunistic behavior, and superior project outcomes
than traditional DBB (Sanderson et al., 2018).
Training
Training positively correlates with performance management reform implementation (Kroll &
Moynihan, 2015). Administrations who undergo such training pay more attention to performance
data and strategic planning in their decision-making process. In the face of the new pressures
following the BID, governments could boost their contracting capacity by providing professional
training for procurement and contract officials. Our data suggest that these training efforts should
focus on supply chain management (e.g., alternative delivery methods), project management
(e.g., impact on the environment), and transaction costs management.
Small municipalities need real-world training. There is no one
doing that or teaching anyone. You can follow this manual to a tee,
but it will not help you. There are tips and tricks everyone could
benefit from.” (Chief Procurement Officer, Local Government)
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Flexibility
As construction and infrastructure projects often span years, they tend to operate in changing
environments (e.g., Demirel et al., 2016). Based on the COVID-19 experience, our informants
call for procurement systems to increase transparency and flexibility over the contract lifecycle.
With COVID, things are not as consistent. I think as a person who
holds a contract, as a lead agency, it is helpful to see what projects
are going on. A dashboard would be helpful in that sense.” (Deputy
Commissioner, Local Government)
Managers should also seek a balance between satisfying the multitude of new BID rules
and leaving room for contract managers to use professional judgment. This reinforces our
previous point about the need to boost procurement and contract expertise, especially at the state
and local levels. Our informants suggest that contracts should include flexible control
mechanisms allowing parties to respond to changing conditions. Utilizing an IDIQ contract, for
example, let agencies establish competitively bid prices upfront and procure multiple projects
over a specific period. This eliminates the need to repeat the bidding procedure for every project
and shortens the procurement process. Thus, managers should closely evaluate the type of
contract for each project and resort to demanding types, such as DBB, only when necessary.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Sustainability
The BID strengthens governments’ purchasing power. Being the most prominent buyer on the
market, the government can use its purchasing power to create demand for sustainable
production of goods and services. Although not perfect, government quasi-marketslike all
markets—respond to demand and do so efficiently. In this sense, agencies could use the nature of
markets to generate demand for products that minimize the negative imprint on the environment
and improve social equity (Hafsa et al., 2021). Using purchasing and contracting to achieve
social and environmental policy goals is known as sustainable public procurement (Alkadry et
al., 2019). Examples include quotas for small businesses and companies owned by women and
minorities and requirements to buy local and ensure socially responsible supply chains.
Given the BID’s massive financial boost and local sourcing requirements, there is a
critical opportunity to repurpose government procurement to create market demand for
sustainability (Fiorino, 2010). Less complex project delivery methods can also aid in achieving
such objectives. They can stimulate participation from local small businesses and let government
organizations meet, track, and exceed their inclusion targets.
Concluding Remarks
Infrastructure works worldwide are notorious for their staggering inefficiencies. The McKinsey
Global Institute (2017) has estimated over $270 billion in losses globally due to construction
inefficiencies during the last five years. With the recently passed BID, millions of dollars are at
stake for U.S. public agencies (Statista, n.d.), putting their procurement systems under great
scrutiny. Based on quantitative and qualitative data from the field, this viewpoint identified two
types of deficiencies faced by current procurement systems—organization-wide and
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
construction-specific. We offer recommendations to aid policymakers and public managers in
mitigating these deficiencies and recalibrating the procurement process for the construction
industry. Specifically, our potential solutions center around four pillars—collaboration, training,
flexibility, and sustainability. If correctly managed, the influx of funds through the BID can be a
game-changer for the U.S. economy after the COVID slowdown and can lead to job creation,
better project delivery quality, growth in rural communities, and diffusion of new technologies.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Notes:
1 State procurement offices in Iowa, Maryland, Minnesota, New Mexico, South Carolina,
Vermont, Washington, and West Virginia govern contracting decisions for building construction
only; in DC for highway construction only; and in Hawaii, Illinois, New Hampshire, and Rhode
Island for both building and highway construction (NASPO Survey of State Procurement
Practices, 2018).
2Smith and Meier (1995) and Lowery (1989) draw on education vouchers to show how the
government’s preference for quality education gets replaced by consumers’ preference for
religious services and racial segregation.
3 A public-private partnership (PPP) can be considered an innovative project delivery model that
builds upon the strengths of the design-build delivery (DBB) method. In this sense, PPP is a
particular case of DBB.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
References
Agarwal, Rajat, Chandrasekaran, Shankar, and Sridhar, Mukund. 2016. “Imagining
construction’s digital future.” McKinsey & Company. Accessed September 1, 2022.
https://www.mckinsey.com/industries/capital-projects-and-infrastructure/our-
insights/imagining-constructions-digital-future
AGC The Construction Association. 2021. “Passage Of Bipartisan Infrastructure Bill Will
Provide A Needed Boost To Construction Industry While Making The Economy More
Efficient.” Last Modified November 5, 2021.
https://www.agc.org/news/2021/11/05/passage-bipartisan-infrastructure-bill-will-provide-
needed-boost-construction
Alliance for American Manufacturing n.d.American Workers and Manufacturers Will Benefit
from New Buy America Waiver Guidelines.” Accessed September 1, 2022.
https://www.americanmanufacturing.org/press-release/american-workers-and-
manufacturers-will-benefit-from-new-buy-america-waiver-guidelines/
Alkadry, Mohamad G., Evelyn Trammell, and Ana-Maria Dimand. 2019."The power of public
procurement: social equity and sustainability as externalities and as deliberate policy
tools." International Journal of Procurement Management 12(3): 336-362.
Alsharef, Abdullah, Siddharth Banerjee, SM Jamil Uddin, Alex Albert, and Edward Jaselskis.
2021. "Early impacts of the COVID-19 pandemic on the United States construction
industry." International journal of environmental research and public health 18(4): 1559.
https://doi.org/10.3390/ijerph18041559
Brunjes, Benjamin M. 2022. "Your competitive side is calling: an analysis of Florida contract
performance." Public Administration Review 82(1): 83-101.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Buckley, Peter J. 2020. "China’s Belt and Road Initiative and the COVID-19 crisis." Journal of
International Business Policy 3(3): 311-314.
Center on Budget and Policy Priorities. 2022. “Chart Book: Tracking the Post-Great Recession
Economy.” Last modified March 15, 2022.
https://www.cbpp.org/research/economy/tracking-the-post-great-recession-economy
Christensen, Tom, and Per Lægreid. 2011. "Complexity and hybrid public administration—
theoretical and empirical challenges." Public organization review 11(4): 407-423.
Demirel, Hatice Çiğdem, Wim Leendertse, Leentje Volker, and Marcel Hertogh. 2017.
"Flexibility in PPP contractsDealing with potential change in the pre-contract phase of a
construction project." Construction management and economics 35 (4): 196-206.
Demers, Jasmine. 2020. “Supervisors approve $1.4B budget, fund projects to boost economy
post COVID-19.Last modified August 17, 2020. https://tucson.com/news/local/govt-
and-politics/supervisors-approve-1-4b-budget-fund-projects-to-boost-economy-post-
covid-19/article_1fec38e3-d796-525b-813f-b5153d00966f.html
Dimand, Ana-Maria. 2022. “Congress passes the $1T infrastructure bill – but how does the
government spend that much money?” Accessed March 25, 2022.
https://theconversation.com/congress-passes-1t-infrastructure-bill-but-how-does-the-
government-go-about-spending-that-much-money-165376
Douglas, Scott, and Chris Ansell. 2021. "Getting a grip on the performance of collaborations:
Examining collaborative performance regimes and collaborative performance
summits." Public Administration Review 81(5): 951-961.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
FMI. 2022.. “North American Engineering and Construction Outlook. Second Quarter Edition.”
Accessed September 1, 2022.
https://fmicorp.com/uploads/media/Q2_Outlook_2022_Final.pdf
Gioia, Dennis A., Kevin G. Corley, and Aimee L. Hamilton. 2013. "Seeking qualitative rigor in
inductive research: Notes on the Gioia methodology." Organizational research
methods 16(1): 15-31.
Ernita Joaquin, M., and Thomas J. Greitens. 2012. "Contract management capacity breakdown?
An analysis of US local governments." Public Administration Review 72 (6): 807-816.
Fiorino, Daniel J. 2010. "Sustainability as a conceptual focus for public administration." Public
administration review 70: s78-s88.
Forconstructionpros.com. 2020. “U.S. Transportation Secretary Announces Over $1.2 Billion in
Infrastructure Grants to Airports.” Last Modified September 1, 2020.
https://www.forconstructionpros.com/infrastructure/press-release/21173619/us-
department-of-transportation-us-transportation-secretary-announces-over-12-billion-in-
infrastructure-grants-to-airports
Heintz, James, Robert Pollin, and Heidi Garrett-Peltier. 2009. How infrastructure investments
support the US economy: employment, productivity and growth. Political Economy
Research Institute (PERI), University of Massachusetts Amherst.
Hafsa, Fatima, Nicole Darnall, and Stuart Bretschneider. (2021). Social Public Purchasing:
Addressing a Critical Void in Public Purchasing Research. Public Administration Review.
https://doi.org/10.1111/puar.13438
Illinois Department of Commerce & Economic Opportunity. 2020. “Pritzker administration
announces Nearly $40 million in rebuild Illinois grants to jumpstart capital projects
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
across the state.” Last modified September 19, 2020.
https://www2.illinois.gov/dceo/Media/PressReleases/Pages/PR081920.aspx
Kalesnikaite, Vaiva and Neshkova, Milena. I. 2021. “Problem severity, collaborative stage, and
partner selection in US Cities.” Journal of Public Administration Research and Theory
31(2): 399-415.
Koppenjan, Joop FM, and Bert Enserink. 2009. “Public–private partnerships in urban
infrastructures: Reconciling private sector participation and sustainability.Public
Administration Review 69(2): 284-296.
Kort, Michiel, and ErikHans Klijn. 2011. “Public–private partnerships in urban regeneration
projects: organizational form or managerial capacity?Public Administration Review
71(4): 618-626.
Kroll, Alexander and Moynihan, Donald P. 2015. “Does training matter? Evidence from
performance management reforms.” Public Administration Review 75(3): 411-420.
Locatelli, Giorgio, Giacomo Mariani, Tristano Sainati, and Marco Greco. 2017. “Corruption in
public projects and megaprojects: There is an elephant in the room!” International
Journal of Project Management 35(3): 252-268.
Lowery, David (1998). “Consumer sovereignty and quasi-market failure.Journal of Public
Administration Research and Theory 8(2): 137-172.
Johnston, Erik. 2010. “Governance infrastructures in 2020.” Public Administration Review 70:
s122-s128.
Love, Peter ED, Lavagnon Ika, Jane Matthews, and Weili Fang. 2021. “Shared leadership, value
and risks in large scale transport projects: Re-calibrating procurement policy for post
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
COVID-19.” Research in Transportation Economics, 90, 100999.
https://doi.org/10.1016/j.retrec.2020.100999
Maani, Nason, and Sandro Galea. 2020. “COVID19 and underinvestment in the publi c health
infrastructure of the United States.The Milbank Quarterly 98(2): 250-259.
Mackintosh, Maureen. 1997. “Economic culture and quasim arkets i n l ocal g ov ern m ent: The
case of contracting for social care.” Local Government Studies 23(2): 80-102.
Madeinamerica.com n.d. “Made in America.” Accessed September 1, 2022.
https://www.madeinamerica.gov
McKinsey & Company. 2019. “Governments can lead construction into the digital era.
Accessed September 1, 2022. https://www.mckinsey.com/business-
functions/operations/our-insights/governments-can-lead-construction-into-the-digital-era
McKinsey Global Institute. 2017. “Reinventing construction: a route to higher productivity.
Mckinsey&Company, Research Insight Impact. Accessed September 1, 2022.
https://www.mckinsey.com/~/media/McKinsey/Business%20Functions/Operations/Our%
20Insights/Reinventing%20construction%20through%20a%20productivity%20revolution
/MGI-Reinventing-Construction-Executive-summary.pdf
Messick, Richard. 2020. “Corruption Risks in Infrastructure Projects Using Design-Build
Contracts”. Last modified April 25, 2020.
https://globalanticorruptionblog.com/2020/04/15/corruption-risks-in-infrastructure-
projects-using-design-build-contracts/
Moody’s Analytics. 2021. “Macroeconomic Consequences of the Infrastructure Investment and
Jobs Act & Build Back Better Framework.” Prepared by Mark Zandi and Bernard Yaros.
Accessed September 1, 2022 https://www.moodysanalytics.com/-
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
/media/article/2021/macroeconomic-consequences-of-the-infrastructure-investment-and-
jobs-act-and-build-back-better-framework.pdf
Nasir, Hassan, Hani Ahmed, Carl Haas, and Paul M. Goodrum. 2014. “An analysis of
construction productivity differences between Canada and the United States.
Construction Management and Economics 32(6): 595-607.
Patrucco, Andrea S., Antonella Moretto, and Louise Knight. 2021. “Does relationship control
hinder relationship commitment? The role of supplier performance measurement systems
in construction infrastructure projects.International journal of production economics,
233, 108000. https://doi.org/10.1016/j.ijpe.2020.108000
Patrucco, Andrea S. and Dimand, Ana-Maria. 2021. “Job Order Contracting (JOC) as an
Alternative Project Delivery Method: Challenges and Opportunities.” Accessed
September 1, 2022. https://www.gordian.com/uploads/2021/11/2021-NIGP-Research-
Report-JOC-Project-Delivery-Method.pdf
Pavel, Alexandru, Bogdan Moldovan, Bogdana Neamtu, and Cristina Hintea. 2018. “Are
Investments in Basic Infrastructure the Magic Wand to Boost the Local Economy of
Rural Communities from Romania?Sustainability 10(10): 3384.
doi:10.3390/su10103384
Port Technology International Team. 2020. “Port of Seattle to boost economy with revised
construction plans.” Last updated May 1, 2020.
https://www.porttechnology.org/news/port-of-seattle-to-boost-economy-with-revised-
construction-plans/
Sanderson, Marie, Pauline Allen, Randeep Gill, and Emma Garnett. 2018. “New models of
contracting in the public sector: A review of alliance contracting, prime contracting and
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
outcomebased con tracti n g l i terature. Social Policy & Administration 52(5): 1060-
1083.
Slowey, Kim. 2020. “Troubled I-4 Ultimate to shave months off schedule during shutdown-
related FDOT acceleration program.” Last Modified April 14, 2020.
https://www.constructiondive.com/news/florida-accelerates-21b-of-dot-projects-during-
state-coronavirus-
shutdown/575516/#:~:text=In%20an%20effort%20to%20lessen,%242.1%20billion%20o
f%20transportation%20projects
Sørensen, Eva, and Jacob Torfing. 2021. “Radical and disruptive answers to downstream
problems in collaborative governance?Public Management Review 23(11):1590-1611.
Smith, Kevin B., and Kenneth J. Meier. 1995. “Public choice in education: Markets and the
demand for quality education.” Political Research Quarterly 48(3): 461-478.
Stanton, Thomas H. (2008). “Improving the managerial capacity of the federal government: A
public administration agenda for the next president.” Public Administration Review
68(6): 1027-1036.
Statista n.d. “Construction spending relative to GDP in the U.S. from 2008 to 2017.” Accessed
September 1, 2022. https://www.statista.com/statistics/226361/us-construction-spending-
relative-to-gdp/
U.S. Census Bureau. 2022. “Construction Spending.” Last modified August 1, 2022.
https://www.census.gov/construction/c30/c30index.html
U.S. Bureau of Labor Statistics. 2021. “Labor Productivity and Costs. A Closer Look:
Construction Industries.Last modified September 21, 2021.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
https://www.bls.gov/lpc/construction.htm#:~:text=The%20construction%20sector%20ma
kes%20up,were%20attributable%20to%20this%20sector
U.S. Department of Commerce. 2022. “GDP by Industry. Bureau of Economic Analysis. Last
modified March 2022.” Accessed September 1, 2022.
https://apps.bea.gov/iTable/index_industry_gdpIndy.cfm
U.S. Department of Transportation. 2020. “U.S. Transportation Secretary Elaine L. Chao
Announces $400 Million in Federal Funding Allocations for Four Transit Infrastructure
Projects. Last Modified August 26, 2020. https://www.transportation.gov/briefing-
room/us-transportation-secretary-elaine-l-chao-announces-400-million-federal-funding
U.S. Department of Transportation. 2022. “The INFRA Grants Program.” Last modified March
21, 2022. https://www.transportation.gov/grants/infra-grants-program
The White House. 2021. “Fact Sheet: The Bipartisan Infrastructure Deal.Last updated
November 6th, 2021. https://www.whitehouse.gov/briefing-room/statements-
releases/2021/11/06/fact-sheet-the-bipartisan-infrastructure-deal/
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
FIGURES
Figure 1. Deficiencies of construction procurement systems.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Figure 2. Challenges in public construction procurement (Note: Respondents were asked to what
extent each construction procurement activity is difficult and/or time-consuming, where
1=strongly disagree and 5=strongly agree. These were recoded as High (4 and 5), Medium (3),
and Low (1and 2).
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Figure 3. Proposed solutions to procurement system deficiencies.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
TABLES
Table 1. Construction Procurement Characteristics in Surveyed Public Organizations
Annual spending Number of contracted
projects Number of employees Time to procure a project
<1M 23 6.4% < 25 175 48.3% < 2 61 20.7% < 2 weeks 5 1.4%
1-5M 47 13.0% 25-50 84 23.2% 2-4 96 32.7% 2-4 weeks 21 5.8%
5-10M 51 14.1% 51-75 31 8.6% 5-7 73 24.8% 1-2 months 59 16.3%
10-50M 102 28.1% 76-100 25 6.9% 8-10 32 10.9% 2-4 months 83 22.9%
>50M 139 38.4% >100 47 13.0% > 10 32 10.9% > 4 months 194 53.6%
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
APPENDIX A
Survey Data Collection and Sample Characteristics
We designed and administered the survey from May to September 2021 to assess the current
challenges public procurement systems face in contracting construction projects. The questions
are informed by the extant literature at the intersection of supply chain management, construction
management, and public administration. The questionnaire was pre-tested with 12 senior
procurement officers before being distributed. Based on the feedback, we refined the survey
items. Our target population was public officers tasked with procuring construction projects.
Thus, study participants were not necessarily familiar with the potential implications of the BID
or its technical aspects. While still not passed at the time of the survey, the BID was already in
the works and actively debated in the news media. To reach more organizations, we distributed
the survey through the professional networks of two organizations—NIGP: The Institute for
Public Procurement and Gordian. The study was sent to about 5,000 respondents, 612 initiated
responses, and 362 completed the survey (a response rate of about 7%). Table A reports the
respondent characteristics.
Table A. Characteristics of Surveyed Construction Procurement Officials
Years in the Position Public Organization Type
Total Procurement
Employees
1-5 years 80 22.1% Local government 158 43.7% < 3 63 17.40%
6-10 years 126 34.8% State government 49 13.5% 3-5 85 23.5%
11-15 years 49 13.5% Education institution 46 12.7% 6-10 71 19.6%
>15 years 107 29.6% Healthcare provider 75 20.7% 11-20 51 14.1%
Other public entity 34 9.4% >20 92 25.4%
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
APPENDIX B
Semi-Structured Interviews
We conducted semi-structured interviews with 30 senior public officers tasked with construction
procurement in their organizations. The sample included directors (e.g., Planning and
Development, Parks and Recreation, Public Works, Maintenance and Construction, and Public
Services), facility managers, and purchasing managers. The interview questions inquired about
1) the characteristics of the construction procurement process, 2) the main issues and challenges
that procurement officers face, 3) the project delivery methods used, and 4) suggestions for
improving construction procurement. The interview data were analyzed using an inductive
approachspecific challenges discussed by the interviewees were grouped under broader issues
and categorized as either organization-wide or construction-specific procurement system
deficiencies. Table B contains the coding scheme and exemplary quotes.
Table B. Exemplary quotes for the themes emerged during the interviews with public officers.
Deficiencies
Issues
Challenges (exemplary quotes)
Organizational
deficiencies Managerial issues
Late involvement of procurement in the project definition:
Procurement is brought in very late in the game, [when]
decisions are already made and are underway. Sometimes we
identify an alternative, but it is too late.
Lack of planning:
“Our biggest headache [is] the lack of planning
and the demand for a quick turnaround on
[project] jobs”
Lack of procedure standardization:
We need to streamline the procurement workflow in
governmenttoo many layers of bureaucracy and too many
hands touch the same document; enhancements to a software
dashboard would be great.
“There's no standardization, to look up stuff in there
Staff shortages:
Estimating is the heart. The accuracy estimation rate is 7%! We
also have a big labor crisis, we don’t have enough people to do
the job.
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
Our procurement office is 1.5 FTE, and it is overseen by the
CFO. We have a $300 million operating budget all run by a
single personthis is a severe understaffing.”
Knowledge issues
Lack of knowledge on financial and cost aspects:
They [procurement] struggle with price accuracy. They don't
know what something should cost so rely on the contractors.
I have some spreadsheets for estimating unit costs, but it is a
struggle. There have been changes in the last 12 months with
COVID. I try to do my best with small projects, but for larger
projects, I really need more people able to do a scope review (…)
it really falls under me, but I do not have the capability to
oversee it in a reliable way.
Lack of supply market knowledge:
I don't think there's any training availability. The (name of a
program), all they tell you is the rote legal laws. (Name of
another program), that's a private group you can join, they fail at
dispersing knowledge. Other than that, there is nothing. Small
municipalities need real-world training. There's no one doing
that or teaching anyone. You can follow this manual to a tee, and
it won't help you [to find the best supplier]. There are tips and
tricks everyone could benefit from, in any state.
Lack of expertise in bid evaluation:
We would love more expertise. None of us are experts. When I
hit the light switch, I don't care how it works, I just want it to
turn on.
Construction
procurement
process
deficiencies
Project delivery
method issues
Complexities of the construction procurement process:
We don't have a county government, so the state has a
contracting portal where all the cities/towns can all post their
bids and arrange it that way…it makes everything more
complicated. We never know who's going to show up and takes a
lot to validate contractors…the lowest bidder is not always the
most responsible bidder…I have seen projects done where the
product is not what we really wanted because of the lowest
bidder [we picked].
The process itself is complicated when you get to larger
projects, having to bid out for a month and a half. The other part
is the process within the town, there are a number of approvals
we need to get. It makes it pretty cumbersome. Sometimes it
makes it tougher when you have to get all the documents scanned
and signed.”
Lack of time to execute activities appropriately:
We are always in rush. It takes a long time to get a quote. We
need prices and proposals sooner, so we can have more time to
analyze them.
We cross check bids across each other. We try to make sure we
spell out exactly what we are looking for. We make sure the
warranties cover what we need. We have created estimates on
our own based on previous projects. We sometimes go to cost
databases to get pricing.
Resistance to adopt alternative delivery methods:
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
If they [procurement] can use other tools outside of DBB this
would be a game-changer. It would improve their process to get
the same benefits as a developer.
Just lack of experience with it [other project delivery methods].
We've done things a certain way for a long time, and it's worked.
We probably would need a lot better understanding of how it
works and the benefits in order to get on board.
Supplier evaluation
issues
Unreliable tenders:
We've done a lot of bids, so we understand how it works. My
concern with complex projects is more about getting competitive
prices, not that I don't trust my contractors’ ability to develop a
scope. We do an in-house estimate based on bids from the past
three years. So, we usually get bids around what we estimate, but
is it fair? We don’t know.
Difficulties in finding the right suppliers/receiving competitive
offers:
We are not able to design competitive processes. Sometimes we
only get one bid. Not having enough participation from
contractors. Once you have one contractor doing most of your
stuff, contractors are less interested [to give you the best
performance]. Restrictions from grant and loan requirements
don’t help.”
We do not find enough contractors to bid on a project
There is a lack of people submitting their bids. Especially since
COVID, it has been harder to get them. Contractors have crew
shortages.”
Award contracts “uncompetitively”:
We do all of our procurement ourselves; we don't have separate
agencies…It is hard to get competitive prices and multiple
bidders at a competitive rate.
Sometimes you get a good price, sometimes it works out in your
favor (like an auction) but other times it's the flipside. They [the
suppliers] know how it works and who is not going to go after the
biz so they gouge you on price. The laws are designed to protect
against fraud.
Not getting competitive process […] . Sometimes we only get
one bid. We do not have enough participation from contractors.
Once you have one contractor doing most of your stuff
contractors are less interested.[in bidding]
15406210, ja, Downloaded from https://onlinelibrary.wiley.com/doi/10.1111/puar.13575 by POLITECNICO DI MILANO, Wiley Online Library on [28/10/2022]. See the Terms and Conditions (https://onlinelibrary.wiley.com/terms-and-conditions) on Wiley Online Library for rules of use; OA articles are governed by the applicable Creative Commons License
... Procurement in the public sector has typically been viewed as a basic administrative process involving contract management and the application of specific regulations (Patrucco et al. 2017;Trammell et al. 2020). In recent years, especially in response to the COVID-19 pandemic and economic crisis, it is evident that procurement plays a strategic role in the effective implementation of policy reforms (Patrucco et al. 2022). Research and practice have demonstrated that public procurement can be strategically utilized to improve value for money (e.g., Erridge and Mcllroy 2002;Loader 2007;Reis and Cabral 2015;Patrucco et al. 2017) and public value (e.g., Erridge 2007), increase market innovation (e.g., Edler and Georghiou 2007), achieve social, economic, and environmental goals (e.g., Alkadry et al. 2019), and reduce unemployment and improve working conditions (e.g., Grandia and Meehan 2017). ...
... First, this study extends the current emergency management literature focused on understanding how governments ensure equity in public management decisions, using COVID-19, the most recent global emergency, as the context (e.g., Wright and Merrit 2020). Second, by providing insights into how federal organizations can use procurement and emergency contracting to achieve their broader diversity, equity, and inclusion objectives, we support previous literature (e.g., Patrucco et al. 2022;Plantinga et al. 2020) that promotes the role of procurement for strategic public management. Last, by using the portfolio management theory, this study first shows the strategic application of portfolio models to the public context (so far underutilized; Tip et al. 2022). ...
Article
Full-text available
While the U.S. federal government strives to advance social equity in government contracting through various policies to support small disadvantaged business enterprises (SDBEs), entry barriers persist. Drawing on federal government spending data from the initial response to the COVID‐19 pandemic, this study estimates logistic and multinomial logistic regressions using portfolio management theory to understand what factors can favor SDBE participation in government contracts during the immediate response to emergencies and whether these factors differ when governments award strategic versus non‐strategic contracts. The results show that governments do not necessarily have to reduce competition to favor SDBE participation in government contracts, as some of these suppliers can participate and win competitive procedures. Although non‐SDBE suppliers were still more likely to be awarded contracts during the initial emergency response, SDBE suppliers were more likely to win procedures for strategic and important supplies. This article is protected by copyright. All rights reserved.
Article
Full-text available
This study investigates how green purchasing in local governments varies as a function of the organization's internal commitment, operationalized by the stage of institutionalization of green public procurement (GPP), and external pressures from various stakeholder groups. GPP, a value‐based innovation justified on the grounds of intergenerational equity, is an important tool governments can use to mitigate the adverse effects of climate change. Survey data from 210 U.S. local governments reveal that while both external and internal factors are strong predictors of buying green, internal commitment matters relatively more. We also find that earlier stages of GPP institutionalization are more conducive to external influence, albeit the effect differs among stakeholders. Local governments tend to be more likely to buy green when nudged by nonprofits and interest groups, and less so when offered financial incentives by the federal government.
Technical Report
Full-text available
In 2021, Gordian and NIGP: The Institute for Public Procurement partnered to conduct market research on construction project delivery method challenges and opportunities. The scope of this research was to better understand construction procurement trends, solicitation activities and the differences between project delivery methods. Specifically, the research sought to answer two main questions: 1. Are solicitation, transaction and coordination efforts different when implementing Job Order Contracting compared to other delivery methods? 2. How do contractor relationships and governance of the contract differ when using Job Order Contracting compared to other delivery methods?
Article
Full-text available
Since governments are the largest buyers globally, they have enormous purchasing power. Government purchasing, therefore, has potential to be leveraged to improve social outcomes, such as helping disadvantaged communities, ensuring labor rights, and minimizing negative environmental impacts. However, as yet, there is little understanding about social public purchasing research in the field of public administration. We provide a theoretical framework for organizing research around social public purchasing. We then survey both the scholarly and practitioner research on social public purchasing in order to develop a clear understanding of the critical knowledge gaps and the potential for important social public purchasing research. This article is protected by copyright. All rights reserved.
Article
Full-text available
Competition over the allocation of scarce resources motivates many public policy choices, and increasingly the influences the management of public organizations. With the rise of the businesslike approach espoused by adherents of “new public management,” competitive mechanisms are increasingly used in the public sector as means to improve organization and program performance. Despite the wide acceptance of competition as a viable method to improve public management, little large n empirical work has been done to determine whether competition improves performance, especially in the networked, cross-sectoral setting of modern governance. Analyzing more than 20,000 Florida contracts over a three-year period, this research explores whether competitive sourcing procedures lead to improved contractor performance. Results show that competitive sourcing may be associated with higher contract spending and undesirable contract outcomes. Other factors, including experience, existing relationships, and lower transaction costs, are more likely to lead to better performance. This article is protected by copyright. All rights reserved.
Article
Full-text available
The COVID-19 pandemic has been the largest global health crisis in decades. Apart from the unprecedented number of deaths and hospitalizations, the pandemic has resulted in economic slowdowns, widespread business disruptions, and significant hardships. This study focused on investigating the early impacts of the COVID-19 pandemic on the U.S. construction industry since the declaration of the national emergency on 13 March 2020. The study objectives were achieved through 34 telephone interviews with project managers, engineers, designers, and superintendents that represented different states and distinct industry sectors in the United States (U.S.). The inter-viewees offered information on their experience with the pandemic, including the general and adverse effects experienced, new opportunities created, and risk management efforts being under-taken. The reported adverse effects included significant delays on projects, inability to secure materials on time, reduction in productivity rates, material price escalations, and others. The new opportunities that were created included projects involving the fast-track construction of medical facilities , construction of residential buildings, transportation-related work, and opportunities to recruit skilled workers. The risk management measures that were widely adopted included measures to enhance safety and reduce other project risks. The safety measures adopted included requiring employees to wear cloth face masks, adoption of social distancing protocols, staggering of construction operations, offering COVID-19-related training, administering temperature checks prior to entry into the workplace, and others. Measures to manage other project risks included the formation of a task force team to review the evolving pandemic and offer recommendations, advocating that construction businesses be deemed essential to combat delays and taking advantage of government relief programs. The study findings will be useful to industry stakeholders interested in understanding the early impacts of the pandemic on the construction industry. Industry stakeholders may also build upon the reported findings and establish best practices for continued safe and productive operations.
Article
Full-text available
Though supplier performance measurement systems (SPMS) provide a key tool for buyers to govern supplier relationships and performance, they can have a detrimental impact on trust and commitment, when perceived as just a means of control. SPMS are particularly valuable in sectors characterized by high complexity and variability of supplier performance, such construction. In projects with public sector buyers, regulations can constrain the development of comprehensive SPMS and the establishment of long-term perspectives on buyer-supplier relationships, and the impact of performance measurement practices are less well understood. To explore whether and how control and commitment can be achieved through structured use of SPMS in the public sector, this paper investigates the impact of a systematic approach to supplier performance measurement on project performance (i.e. cost, time, and quality), and how these effects are mediated by commitment. These relationships are tested using structural equation modeling on dyadic survey data collected from both suppliers and public buyers in 206 construction infrastructure projects in Italy. Results show that more rigorous qualification and performance evaluation processes have a positive impact on project performance, whereas this is not the case for supplier selection processes. Supplier commitment has a positive mediating role on the relationship between performance evaluation and project performance, while buyer commitment negatively mediates the impact of a more rigorous qualification process. These findings inform our understanding of the trade-off between control and commitment, focusing on public buyer-supplier relationships in construction projects. They demonstrate the differential relevance of SPMS to final performance across phases of the contracting cycle, and the contrasting impact of buyer and supplier commitment.
Article
Full-text available
Collaborative governance is popular among practitioners and scholars, but getting a grip on the performance of collaborations remains a challenge. Recent research has made progress by identifying appropriate performance measures, yet managing performance also requires appropriate performance routines. This article brings together insights from collaborative governance and performance management to conceptualize collaborative performance regimes; the collection of routines used by actors working together on a societal issue to explicate their goals, exchange performance information, examine progress, and explore performance improvement actions. The concept of regimes is made concrete by focusing on the specific routine of organizing a collaborative performance summit; a periodic gathering where partners review their joint performance. Such summits are both manifestations of the performance regime and potential turning points for regime change. Using three local public health collaborations as illustration, this articles offers a framework for understanding collaborative performance regimes, summits, and the dynamics between them. This article is protected by copyright. All rights reserved.
Article
Full-text available
Before the 2019 Coronavirus Disease (COVID-19) outbreak, the Australian Commonwealth and State Governments invested significantly in the upgrade and construction of large-scale transport infrastructure projects (>AU$500 million). However, two trends prevail in Australia. Concessionaires/contractors face a requirement for fixed-price contracts, high levels of risk, and low margins. Concomitantly, an increasing number of projects have experienced significant cost blowouts, with adverse impacts on both the public and private sectors. Calls for the public sector to engage with collaborative procurement approaches to deliver large-scale transport projects, however, have gone unheeded. In this paper, we critically review existing procurement policies and practices used to procure large-scale transport projects and examine their procurement challenges, particularly in a post-COVID-19 world. We suggest that the public and private sectors will need to work in unison to overcome the significant economic hurdles that COVID-19 presents to the nation's infrastructure demands. We then proffer that governments need to re-calibrate their procurement policies to future-proof their large-scale transport infrastructure projects. To facilitate the process of re-calibration, we develop a theoretical procurement framework for consideration based on the concepts of shared leadership, value creation, and risks. It is envisaged that our procurement framework will provide a platform for engendering economic value and accounting for all-important societal costs and benefits in a world post pandemic.
Article
The research on collaborative governance has focused on the upstream problems concerning the recruitment of actors, facilitation of collaboration and the fostering of agreement. However, the main problems are possibly located downstream after a decision is made and thus relate to the implementation of joint solutions the evaluation of the results and the attempt to hold the actors to account. Base on new theoretical developments, this article explores some radical and disruptive responses to these downstream problems. Or findings is that while these responses are making good progress in solving downstream problems, we are not quite there yet.
Article
Prior research identifies problem severity as an important antecedent of collaboration. Yet, little is known about how problem severity shapes collaborative behavior of public organizations beyond the initial decision to engage in such action. This study adds to the theory of collaboration by linking problem severity to the stage of collaborative activity and partner selection. We empirically test the validity of these linkages in the context of US local governments and examine how they respond to a wicked public problem—sea-level rise. The analysis draws on 2017 survey data from 140 vulnerable municipalities across 20 states. We find that cities respond to higher risk by increasing their collaborative effort and seeking partners across sectors, with preference for those less similar to them. Our results remain robust to three objective measures of problem severity, as well as to a perception-based measure. A closer examination of the interplay between the effect of real and perceived threat underscores the need to account for the views of local decision makers.