ArticlePDF Available

Abstract and Figures

This paper aims to analyze the main causes of disputes which occur in the construction industry. In order to reach this aim, a literature review was undertaken to identify the common construction disputes. The disputes derived from a cross-section of the literature, were classified into main categories and the main causes of construction disputes were determined. Finally, an analysis was carried out using the analytical network process (ANP) approach to determine their relative importance. (C) 2014 The Authors. Published by Elsevier Ltd.
Content may be subject to copyright.
Procedia - Social and Behavioral Sciences 109 ( 2014 ) 183 – 187
1877-0428 © 2014 The Authors. Published by Elsevier Ltd.
Selection and peer review under responsibility of Organizing Committee of BEM 2013.
doi: 10.1016/j.sbspro.2013.12.441
ScienceDirect
2nd World Conference On Business, Economics And Management -WCBEM 2013
An analysis of causes of disputes in the construction industry using
analytical network process
Emre Cakmak a, Pinar Irlayici Cakmak b*
aOkan University, Istanbul, 34959,Turkey
bIstanbul Technical University, Istanbul, 34437, Turkey
Abstract
This paper aims to analyze the main causes of disputes which occur in the construction industry. In order to reach this aim, a
literature review was undertaken to identify the common construction disputes. The disputes derived from a cross-section of the
literature, were classified into main categories and the main causes of construction disputes were determined. Finally, an analysis
was carried out using the analytical network process (ANP) approach to determine their relative importance.
1. Introduction
The construction industry is a complex and competitive environment in which participants with different views,
talents and levels of knowledge of the construction process work together. In this complex environment, participants
from various professions, each has its own goals and each expects to make the most of its own benefits. In the
construction industry, since differences in perceptions among the participants of the projects, conflicts are
inevitable. If conflicts are not well managed, they quickly turn into disputes. Disputes are one of the main factors
which prevent the successfully completion of the construction project. Thus, it is important to be aware of the causes
of disputes in order to complete the construction project in the desired time, budget and quality.
There are confusion among construction professionals about the differences between conflict and dispute, and
these terms have been used interchangeably especially in the construction industry (Acharya et al., 2006). However,
according to Fenn et al. (1997) conflict and dispute are two distinct notations. Conflict exists wherever there is
incompatibility of interest. Conflict can be managed, possibly to the extent of preventing a dispute resulting from the
conflict. On the other hand, disputes are one of the main factors which prevent the successfully completion of the
construction project. Disputes are associated with distinct justiciable issues and require resolution such as mediation,
negotiation arbitration, etc.
This paper aims to analyze the main causes of disputes which occur in the construction industry. In order to reach
this aim, a literature review was undertaken to identify the common construction disputes. The main causes of
* Corresponding Author: Pinar Irlayici Cakmak. Tel.: +90-212-293-1300
E-mail address: irlayici@itu.edu.tr
Keywords: Analytical network process (ANP), causes of disputes, construction disputes, construction industry;
Available online at www.sciencedirect.com
© 2014 The Authors. Published by Elsevier Ltd.
Selection and peer review under responsibility of Organizing Committee of BEM 2013.
184 Emre Cakmak and Pinar Irlayici Cakmak / Procedia - Social and Behavioral Sciences 109 ( 2014 ) 183 – 187
construction disputes were determined by the help of the literature review. The disputes derived from the literature,
were classified into main categories and their sub categories. Finally, an analysis was carried out using the analytical
network process (ANP) approach to determine their relative importance.
2. Causes of disputes in the construction industry
There has been considerable research undertaken to determine the causes of disputes in the construction industry.
A literature review has been conducted in order to overview the causes of construction disputes. Several researches
from different countries have been analyzed. Then, a table, adapted from Kumaraswamy (1997), is created which
summarizes the causes of disputes which are determined by several researchers from different countries (Cakmak
and Cakmak, 2013).
The causes of disputes are first examined and identified through a relevant literature review. Although researches
have concentrated on various causes of disputes, there is a certain level of commonality in the causes of disputes
(Cakmak and Cakmak, 2013). In this context, it is necessary to classify the common causes of disputes into
categories. The causes of disputes are classified into seven broad categories depending on their nature and mode of
occurrence. As a result, 28 common causes of dispute are selected for further examination in this study (Table 1).
Table 1: Common causes of disputes by categories
Category of Disputes Causes of Disputes
Owner related (A)
variations initiated by the owner (A1)
change of scope (A2)
late giving of possession (A3)
acceleration (A4)
unrealistic expectations (A5)
payment delays (A6)
Contractor related (B)
delays in work progress (B1)
time extensions (B2)
financial failure of the contractor (B3)
technical inadequacy of the contractor (B4)
tendering (B5)
quality of works (B6)
Design related (C)
design errors (C1)
inadequate / incomplete specifications (C2)
quality of design (C3)
availability of information (C4)
Contract related (D)
ambiguities in contract documents (D1)
different interpretations of the contract provisions (D2)
risk allocation (D3)
other contractual problems (D4)
Human behavior related (E)
adversarial / controversial culture (E1)
lack of communication (E2)
lack of team spirit (E3)
Project related (F) site conditions (F1)
unforeseen changes (F2)
External factors (G)
weather (G1)
legal and economic factors (G2)
fragmented structure of the sector (G3)
185
Emre Cakmak and Pinar Irlayici Cakmak / Procedia - Social and Behavioral Sciences 109 ( 2014 ) 183 – 187
The data in Table 1 is used in the process of analytical network process (ANP) approach for determining disputes'
relative importance.
3. The analytical network process
Saaty (1980) first proposed the analytic hierarchy process (AHP) which is a strong and flexible multi-criteria
decision analysis approach. The AHP helps decision makers set priorities and choose the best alternative when both
qualitative and quantitative aspects are considered. The analytical network process (ANP), also introduced by Saaty,
is a generalization of the AHP (Saaty, 1996). While the AHP represents a framework with a uni-directional
hierarchical AHP relationship, the ANP allows for complex interrelationships among decision levels and attributes.
The ANP has four main steps: (1) problem structuring and model construction, (2) preparation of pair-wise
comparison matrices and priority vectors, (3) supermatrix formation and (4) selection of the best alternative.
The model is built from the top starting with the main dispute causes, then the more specific (sub-categories)
ones. Seven main dispute causes are included in the first level of hierarchy and 28 sub dispute causes in the second
level, as shown in Table 1. All of the main dispute causes and sub dispute causes are given a code letter. These
codes will be used in the supermatrix. Once the hierarchy structure is established, the decision-making process can
take place.
The decision-making process has been carried out by a team of experts who have enough experience related to
construction disputes. First of all, the ANP approach was explained to the experts. Interrelations between each
dispute category were established with a network diagram by experts (Figure 1). Then, the experts derived ratio-
scale (as shown in Table 2) priorities reflecting the relative importance of dispute causes via pair-wise comparisons.
Figure 1. Dispute categories network diagram
Goal
Owner
Related
Contractor
Related
Design
Related External
Factors
Human
Behavior
Related
Project
Related
Contract
Related
186 Emre Cakmak and Pinar Irlayici Cakmak / Procedia - Social and Behavioral Sciences 109 ( 2014 ) 183 – 187
The pair-wise comparisons were done with respect to overall goal of the model: analyzing main causes of
construction disputes. Table 2 shows an example for category of disputes and their comparison values. The experts,
in this particular example in Table 2, assigned the "owner related disputes" a weight of 4 compared with the
"contractor related disputes". Thus, the experts consider the "owner related disputes" to be moderately more
important than the "contractor related disputes" as a dispute category.
Table 2: Pair-wise comparison for dispute categories
A B C D E F G
Owner related (A) 1 4 4 1/7 6 6 8
Contractor related (B) 1/4 1 1/5 1/7 6 6 7
Design related (C) 1/4 5 1 1/7 7 4 7
Contract related (D) 7 7 7 1 9 8 9
Human behavior related (E) 1/6 1/6 1/7 1/9 1 1/6 5
Project related (F) 1/6 1/6 1/4 1/8 6 1 7
External factors (G) 1/8 1/7 1/7 1/9 1/5 1/7 1
When the pair-wise comparisons were completed, the super matrix was constructed. Super matrix was
constructed in Super Decisions, a software program developed for ANP applications. Then, the relative importance
of causes of disputes was identified by considering interrelationships between them.
All main dispute categories, their sub-categories and their normalized relative importance values are presented in
Table 3.
Table 3: Relative importance of disputes causes by categories
Main Categories Relative importance of main
cate
g
ories Sub-categories Relative importance of sub-
cate
g
ories
Owner related 0.081163
variations initiated b
y
the owner 0.011806
chan
g
e of sco
p
e 0.018216
late giving of possession 0.000382
acceleration 0.000171
unrealistic ex
p
ectations 0.002524
p
a
y
ment dela
y
s 0.048064
Contractor related 0.301548
dela
y
s in work
p
ro
g
ress 0.151231
time extensions 0.122495
financial failure of the contractor 0.000127
technical inadequacy of the contractor 0.000171
tenderin
g
0.000101
q
ualit
y
of works 0.027423
Design related 0.253987
design errors 0.054377
inade
q
uate / incom
p
lete s
p
ecifications 0.119561
quality of design 0.071209
availabilit
y
of information 0.008840
Contract related 0.259314
ambi
g
uities in contract documents 0.045363
different interpretations of the contract
p
rovisions 0.019974
risk allocation 0.027686
other contractual
p
roblems 0.166291
Human behavior
related 0.026826
adversarial / controversial culture 0.003531
lack of communication 0.016504
lack of team s
p
irit 0.006792
Project related 0.037032 site conditions 0.018516
unforeseen chan
g
es 0.018516
External factors 0.040127
weather 0.002434
le
g
al and economic factors 0.031776
fra
g
mented structure of the sector 0.005917
187
Emre Cakmak and Pinar Irlayici Cakmak / Procedia - Social and Behavioral Sciences 109 ( 2014 ) 183 – 187
As it is shown in Table 3, "contractor related disputes" has the highest relative importance value with the value of
0.301548. In other words, "contractor related disputes" are the common ones in the construction industry. In this
study, contractor related disputes consist six different sub-disputes causes. These sub-dispute causes and their
relative importance values are: delays in work progress (0.151231), time extensions (0.122495), financial failure of
the contractor (0.000127), technical inadequacy of the contractor (0.000171), tendering (0.000101), and quality of
works (0.027423). When all sub-dispute causes evaluated together, it can also be seen that, "contractual problems"
has the highest relative importance with the value of 0.166291. In other words, "contractual problems" is an
important dispute cause in the construction industry. Other common dispute causes are "delays in work progress",
"time extensions", "inadequate / incomplete specifications", "quality of design", and "design errors" all with relative
importance values higher than 0.050. On the other hand, project related and human behavior related dispute causes
are the least common dispute causes with the relative importance value of 0.037032 and 0,026826 respectively.
4. Conclusion
In this paper, the main causes of dispute causes in the construction industry were analyzed. First of all, the main
causes of construction disputes were determined with a comprehensive literature review. Then, the disputes derived
from the literature, were classified into main categories. According to the classification, main disputes categories
were found as; owner related disputes, contractor related disputes, design related disputes, contract related disputes,
human behavior related disputes, project related disputes and external factors. All these disputes categories have
their own sub-dispute causes. After determining the dispute causes, an approach was carried out using the ANP and
an ANP model was developed. The model considers the relevant dispute causes which occur in the construction
projects. Finally, an analysis was carried out to identify the relative importance of the different dispute causes. The
analysis reveals that the contractor related disputes and their sub-dispute categories are the most common ones in the
construction industry.
References
Acharya, N.K., Lee, Y.D., & Im, H.M. (2006). Conflicting factors in construction projects: Korean perspective. Journal of Engineering,
Construction and Architectural Management, 13, 6, 543-566.
Fenn, P., Lowe, D., & Speck, C. (1997). Conflict and dispute in construction. Construction Management and Economics, 15, 6, 513-518.
Kumaraswamy, M.M. (1997). Conflicts, claims and disputes in construction. Engineering, Construction and Architectural Management, 4, 2, 95-
111.
Cakmak, P.I., & Cakmak, E. (2013). An analysis of causes of disputes in the construction industry using analytical hierarchy process (AHP). AEI
2013 Architectural Engineering Institute Conference, 3-5 April, The Pennsylvania State University, University Park, Pennsylvania, USA.
Saaty, T.L. (1980). The Analytical Hierarchy Process. McGraw-Hill, New York.
Saaty, T.L. (1996). Decision Making with Dependence and Feedback: The Analytic Network Process. RWS Publications, Pittsburgh.
... Chua (2012) conducted a study in Malaysia and Singapore and identified that the top three causes of construction dispute were finance and payment issue, disagreement on claims and variation orders. Cakmak and Cakmak (2014) conducted a literature review and identified 28 causes of dispute in construction industry and grouped them into seven categories (owner related, contractor related, design related, contract related, human behavior related, project related and external factors). The authors used analytical network process analysis and concluded that the most important causes of disputes were delays in work progress, EoT, inadequate specifications, quality of design and design errors. ...
... It is undeniable that the complexity of the construction industry, which involve multiple stakeholders, such as developers, contractors and engineers, required proper communication, to avoid misunderstanding and disputes. Discrepancy occurs in Turkey as this factor was ranked as last in the study that conducted by Cakmak and Cakmak (2014). This may due to the differences in the culture of Sarawak and Turkish construction industry. ...
... Such delay could possibly lead to contractors' claim being delayed and hence increased their risk of project delay (Mahamid, 2016). Cakmak and Cakmak (2014) reported that the construction industry in Turkey is quite matured and the issue of late delivering site possessions seldom occurred, and hence the finding reported this cause of dispute as the least important. The Mann-Whitney U-test result showed a p-value of 0.004, which indicated a significant difference between the viewpoint of Group 1 and Group 2 contractors. ...
Article
Construction dispute contributing to the involvement of billions US dollars in lawsuits and Asia was reported as the continent that had the highest dollars involved. Sarawak, the largest state in Malaysia, faced similar issues and such dispute had been reported in leading to cost and time overrun on the multiple large-scale construction projects. This research investigates factors causing dispute within Sarawak construction industry, by targeting G7 contractors, who has no limitation in handling the scale of project, by using simple random sampling method. Eighty-six contractors responded to the online questionnaire, amounting to 34% valid response rate. Descriptive statistics and Mann-Whitney U-test were used to investigate the viewpoint of respondents. The findings revealed that delay issue as the key cause of dispute to the contractors in Sarawak. Mann-Whitney U-test showed statistical significant differences on the perspectives of contractors between less than or equal to 10 years working experiences and more than 10 years experiences on four causes: poor cost management, finance issue, delay issue and different interpretation of contract provisions. This research could serve as a guideline for the contractors in handling dispute to improve construction companies’ profit margin and construction projects’ efficiency.
... claimed that conflicts and disputes can happen at any stage of a project lifecycle, which can affect its pre-planned schedule, and adversely affect the construction cost, project delivery, and the overall project performance. Following this perspective, several studies (Ayudhya, 2011;Assaf et al., 2019;Cakmak & Cakmak, 2014;El-Sayegh et al., 2020) have classified the causes of disputes based on their common relationships, or by construction stages, or based on the individuals that started the disputes. The results of this study on a framework design that could reduce disputes at various stages of building construction projects are presented in this paper. ...
Article
Full-text available
The upward trend of dispute claims and occurrences throughout different stages has detrimentally affected the outcomes of construction projects. Building upon two major themes from a systematic literature review (SLR) study, Principal Component Analysis (PCA) was performed to further group the extensive causes and strategies into several meaningful groups using the Statistical Social Package Science (SPSS) software. Questionnaires were used and issued to three main stakeholders (clients, consultants, and contractors) in the Klang Valley area. This paper presents the PCA findings, which have led to the development of a framework to prevent disputes in different stages of building construction projects. The PCA findings have narrowed down the major contributors of disputes to “Contract-related causes” and “Time-related causes”. PCA analysis has also shown that the three key themes of “Quality-related strategies,” “Business relationship-related strategies,” and “Productivity-related strategies” were the most effective ways to reduce disagreements. It is important to highlight that the findings related to the causes of disputes during the planning stage consistently align with those of a prior study. This underscores the importance of ethical conduct, particularly during the planning phase and, more specifically, within the tendering process.
... A key aspect of the AHP is that decision criteria are evaluated with respect to their relative importance allowing trade-offs between them [54,106]. It helps decision-makers to set their priorities and to choose the best alternatives when both quantitative and qualitative aspects are considered [107]. The AHP consists of three steps: hierarchy formation (the decision goal), pairwise comparisons (decision-makers), and verification of consistency (EJs) [51,108]. ...
Article
Full-text available
Contingency is a critical component in the cost estimation process for any construction project. The contingency reserve considers potential costs related to risks and uncertainties associated with construction projects. It is usually assumed to damp any resulting uncertain monetary impact and to prevent project cost overrun. Many contingency calculation methods for construction projects proposed in literature ranged from simple percentage to complex mathematical methods. Deciding the optimum contingency method for a given project at a given phase represents the main challenge in cost estimation process. This study presents a comprehensive compilation of all contingency calculation methods and divided them into three main groups: deterministic, probabilistic, and modern mathematical methods which have been discussed in details. Appropriate method for estimating contingency amount depends on many criteria such as project peculiarity, complexity, ease of method used, and the accuracy level of the estimates. This study proposed a practical guidance approach for construction agencies to choose their appropriate cost contingency method. This research is expected to help agencies/owners in the budget development stage to allocate a contingency budget for their construction projects.
... Cheung and Pang (2013) identified the key causes that can lead to disputes in construction projects and proposed a framework that differentiates two types of disputes: speculative and contractual. Moreover, Cakmak and Cakmak (2014) classified disputes into several types, including those that were connected to contracts, projects, contractors, owners, human behavior, design, and external factors. Kumar Viswanathan et al. ...
Article
Construction bidding is a complex process that involves several potential risks and uncertainties for all the stakeholders involved. Such complexities, risks, and uncertainties, if uncontrolled, can lead to the rise of claims, conflicts, and disputes during the course of a project. Even though a substantial amount of knowledge has been acquired about construction disputes and their causation, there is a lack of research that examines the causes of disputes associated with the bidding phase of projects. This study addresses this knowledge gap within the context of infrastructure projects. In investigating and analyzing the causation of disputes related to the bidding stage, the authors implemented a multistep research methodology that incorporated data collection, network analysis (NA), spectral clustering, and association rule analysis (ARA). Based on a manual content analysis of 94 legal cases, the authors identified a comprehensive list of 27 causes of disputes associated with the bidding stage of infrastructure projects. The NA results indicated that the major common causes leading to disputes in infrastructure projects comprise inaccurate cost estimates, inappropriate tender documents, nonproper or untimely notification of errors in a submitted bid, nonproper or untimely notification of errors in tender documents, and noncompliance with Request for Proposals' (RFP) requirements. Upon categorizing and clustering the causes of disputes, the ARA results revealed that the most critical associations are related to differing site conditions, errors in submitted bids, unbalanced bidding, errors in cost estimates, and errors in tender documents. This study promotes an in-depth understanding of the causes of disputes associated with the bidding phase within the context of infrastructure projects, which should better enable the establishment of proactive plans and practices to control these causes as well as mitigate the occurrence of their associated disputes during project execution.
Article
Purpose The construction industry is complex, human-intensive and driven by monetary values. Hence, disputes are widespread. Initial conflicts among parties may develop into a disastrous dispute that costs the project success and good relationships and affects stakeholders' expectations. There has been a focus on causes of construction-related disputes, and studies over the past three decades have attempted to identify a more comprehensive list of reasons for disputes. Some of these studies' limitations were geographical, project delivery methods and project types. The purpose of this study is to identify the most recent and conclusive list of causes of disputes based on current literature by undertaking a systematic literature review (SLR). Design/methodology/approach Considering the large number of studies that focused on causes of disputes, this study aims to develop a comprehensive list of causes, using a SLR, as it ensures that all previous articles in multiple databases are reviewed to produce a comprehensive outcome. A six-stage SLR was followed from background study to analysis and reporting. Findings Not surprisingly, the number of publications has increased over time, most from the Middle East region. The interconnected nature of the causes was widely emphasised. The SLR has produced eight common core causes of disputes. They are: poor contractual arrangements, employer-initiated scope changes, unforeseen site changes, poor contract understanding and administration, contractor’s quality of works, the inability of the contractor to achieve time targets, non- or delayed payments and poor quality of design. The majority of previous authors realised that disputes could be avoided by parties’ involvement during the early stages, avoiding being opportunistic and acting collaboratively. Originality/value Even though numerous studies have been carried out to identify the causes of disputes in the construction industry, none did a SLR. This study aggregates all the previous studies that focused on construction-related disputes systematically. Categorising causes based on the party primarily responsible help various stakeholders by providing a distinct list of factors to avoid that contribute to disputes.
Article
Full-text available
Despite their promising potential, the level of implementation of smart contracts is not at the desired level. To expedite the acceptance and deployment of smart contracts, the barriers to the implementation of smart contracts should be revealed. Past studies, however, do not provide a comprehensive theoretical basis due to several methodological drawbacks. Thus, this study aims to identify and assess the barriers to the implementation of smart contracts by considering the inherent characteristics of the construction industry. An in-depth literature review was initially conducted to extract all barriers proposed in the literature. Then, focus group discussion (FGD) sessions were conducted with the participation of the construction practitioners. In the FGD session, the results of the literature review were validated, and nine additional barriers were proposed. Finally, a total of 20 barriers under five categories was proposed for the smart contract adoption in the construction industry. Then, a questionnaire survey was conducted with the participation of 15 construction practitioners. Lastly, fuzzy VIKOR analysis was performed to assess the criticality of the implementation barriers. This study indicates that the construction companies should overcome not only technical barriers but also managerial barriers. Changes in the processes arisen due to smart contract implementation prevent the construction from implementing a smart contract, since the employees show resistance to these changes. Furthermore, the companies believe that they can lose their bargaining power with smart contracts, and they do not want to lose their power. Bottlenecks are considered the most critical barrier from a technological perspective, and companies are concerned about the problems resulting from them. Although this study provides insights into the barriers to smart contracts in the construction industry, all the respondents are from Turkey. Therefore, some of the findings of this study can be specific to the Turkish construction industry.
Article
Purpose The purpose of this paper is to propose a decision support framework that can be used by decision-makers to identify the most convenient disruption analysis (DA) methods for megaprojects and their stakeholders. Design/methodology/approach The framework was initially developed by conducting a comprehensive literature review to obtain extensive knowledge about disruption management and megaprojects. Focus group discussion (FGD) sessions with the participation of the construction practitioners were then organized to validate and strengthen the findings of the literature review. Consequently, 17 selection factors were identified and categorized as requirement, ability and outcome. Lastly, the most convenient DA methods for megaprojects were identified by performing integrated fuzzy analytical hierarchy process (AHP) and fuzzy technique for order of preference by similarity to ideal solution (TOPSIS) analysis. Additionally, consistency analysis was also conducted to verify the reliability of the results. Findings The results revealed that the measured mile method is the most appropriate DA method for megaprojects. In case the measured mile method cannot be adopted due to various technical and contractual reasons, the decision-makers are proposed to consider program analysis, work or trade sampling, earned value analysis and control chart method, respectively. Second, the selection factors such as “Comprehensible analysis procedure,” “Existing knowledge and experience about a particular DA method,” “Ability to resolve greater number of disruption events,” “Ability to resolve complex disruption events,” “Ability to exclude factors that are not under the owner's responsibility” and “General acceptance by practitioners, courts, and arbitration, etc.” were given the top priority by the experts, highlighting the critical aspects of the DA methods. Originality/value Disruption claims in megaprojects are very critical for the contractors to compensate for the losses stemming from disruption events. Although the effective use of DA methods maximizes the accuracy and reliability of disruption claims, decision-makers can barely implement these methods adequately since past studies neglect to present extensive knowledge about the most convenient DA methods for megaprojects. Thus, developing a decision support framework for the selection of DA methods, this study is the earliest attempt that examines the mechanisms and inherent differences of DA methods. Additionally, owing to the robustness and versatility of this research approach, the research approach could be replicated also for future studies focusing on other project-based industries since disruption is also a challenging issue for many other industries.
Article
Full-text available
This study examines the major causes of disputes and dispute resolution methods used in the construction industry with a view towards suggesting possible ways through which dispute can be controlled, mitigated, or eliminated. The random sampling technique was used to sample construction stakeholders and professionals (Clients, Contractors, Quantity Surveyors, Builders, Architects, Civil Engineers) identified in the study area. Data analysis was carried out using frequencies, percentile, and Mean Item Score (MIS) through the use of a well-structured questionnaire. Result of this study proved that irrespective of the fact that disputes and dispute resolution methods are not new philosophy in the construction industry, undefined channel of communication, diversity in expertise of project participants, and difference in interests, concerns, training and perceptions of individuals involved in the construction project has proven to be the major causes of construction dispute. Therefore, this research outlined excellent planning with the project team members before works begin to ensure that you will finish on time, careful understanding and negotiation of the contract terms and conditions with the client, and documentation of daily report of defects that may arise during project execution as the best possible ways of mitigating construction dispute in the construction industry. The study recommends among others that strict adherence to the outlined possible ways of mitigating construction disputes be practiced amongst construction participants and stakeholders in other to eliminate the negative effects of disputes in the Nigerian construction industry.
Conference Paper
The construction industry is a service sector that is often faced uncertain circumstances with a high rate of changes in its project operations. These changes not only often occur in the implementation (build) phase of a construction project, but it also happens in the planning (design) phase. In general, dealing with such uncertain circumstances means to have the possibility for failure in achieving the goals of a project. Even though changes and adjustments are common in this sector, it nevertheless will bring risks to the construction works. For example, the time, costs, and quality. Hence, a preventive system is needed with which can minimise the risks that may arise during the project activities. The objective of this research is to identify the caused factors of the risks on the construction business, and that to further suggest the applicable model as the preventive action of the risks. This study began with a detail review to seven risk indicators; Labour Risk (X 1 ), Contractual Risk (X 2 ), Human Resources Risk (X 3 ), Design and Technology Risk (X 4 ), Material and Tool Risk (X 5 ), Implementation Risk (X 6 ), and Force Majeure Risk (X 7 ). This research was developed further using questionnaires and expert validation as the primary data, which furthermore analysed using analysis factors, descriptive analysis, and probability impact matric in order to determine the level of the risks. The risk level analysis resulted three variables as the top event (dominant risk), which are X 1 , X 3 and X 4 . These findings were then advanced following Bowtie diagram and scenario analysis, hence suggested a modelling that described possible preventive and corrective strategies. Both the Bowtie diagram and scenario analysis are not only helpful as the guidance and warning, but also practical for the construction practitioners in managing the risk management and decision making for the construction project.
Article
Full-text available
'Conflict' and 'dispute' are two distinct notions. The conceptual difference between the two is explored and further reviewed through the literature on conflict and dispute in the field of construction; a taxonomy for future study is also introduced. Conflict, it is proposed, exists wherever there is incompatibility of interest, and therefore is pandemic. Conflict can be managed, possibly to the extent of preventing a dispute resulting from the conflict. Dispute is associated with distinct justiciable issues. Disputes require resolution. This means that they can be managed: the process of dispute resolution lends itself to third party intervention. The construction industry and the chemical process industry in the UK are compared, through perceptions and experiences of conflict and disputes arising from their two sets of standard contract forms. The methodology is a review of published cases and a survey conducted among professionals with experience. The paucity of research in this field is discussed and the empirical work on the causes of conflict and dispute is reviewed. It is concluded that effective management of conflicts and disputes would be furthered by separating the two fields, and particularly by applying a more stringent structuring.
Article
It is necessary and useful to differentiate destructive from constructive conflict and avoidable from necessary claims; and also to minimize disputes arising from unresolved conflict and claims in construction projects. This paper analyses such needs and proposes means of meeting them through an appropriate classification of construction claims; an estimation of their relative significance in terms of magnitude and frequency; and an identification of the proximate and root causes of the significant claims. A hierarchy of such claims, proximate and root causes is presented, based mainly on data collected from 61 projects and on 46 responses to questionnaires in Hong Kong. Measures of the relative significance of the claims categories are also presented. The results are reinforced by observations from parallel studies in Hong Kong and elsewhere, as well as from the literature. Strategies are suggested to avoid the avoidable and mitigate the unavoidable or unavoided claims, through controlling the controllable causes. Management focus is also recommended on controlling the causes of those categories of claims and disputes that are seen to be significant in terms of higher impact and/or probability of occurrence.
Conference Paper
In the construction industry, since differences in perceptions among the participants of the projects, conflicts are inevitable. If conflicts are not well managed, they are quickly turn into disputes. Disputes are one of the main factors which prevent the successfully completion of the construction project. Thus, it is important to be aware of the causes of disputes in order to complete the construction project in the desired time, budget and quality. This paper aims to analyze the main causes of disputes which occur in the construction industry. In order to reach this aim, a literature review was undertaken to identify the common construction disputes. The disputes derived from a cross-section of the literature, were classified into main categories and the main causes of construction disputes were determined. Finally, an analysis was carried out using the analytical hierarchy process (AHP) approach to determine their relative importance.
Article
Purpose – The purpose of this article is to identify and explore pertinent conflicting factors in construction projects; which would be helpful for project planners and implementers in assessing and taking proactive measures for reducing the adverse effect of conflict. Design/methodology/approach – To achieve the study objectives, a 43‐item questionnaire survey in a five‐point Likert scale was carried out to collect professionals' experience on conflicting activities in Korean construction projects. Responses from 124 professionals working for owners, consultants and contractors were analyzed. Furthermore, ten face‐to face interviews were also carried out to ratify the findings from the field survey. Later, analytical hierarchical process method was employed to find out the importance weighting as well as responsible party for the perceived conflicts. Findings – This study has found out six critical construction conflicting factors pertinent in Korean context. These factors with importance weighting are: differing site condition (24.1 percent), public interruption (22.5 percent), differences in change order evaluation (21 percent), design errors (17.1 percent), excessive contract quantities variation (8.2) and double meaning of specifications (7.1 percent). The study has revealed that owner (35.6 percent) and consultant (34.18 percent) are mostly responsible parties for conflicts in construction projects. Originality/value – As the previous researches have been indicating increase in conflicts in construction field, this paper is very topical at the moment. This work has tried to explore the underlying problems of the construction field. The study provides field level experiences from which the inexperience construction site professionals could learn the instances of conflicts and not repeat the mistakes in their projects.
It is necessary and useful to differentiate destructive from constructive conflict and avoidable from necessary claims; and also to minimize disputes arising from unresolved conflict and claims in construction projects. This paper analyses such needs and proposes means of meeting them through an appropriate classification of construction claims; an estimation of their relative significance in terms of magnitude and frequency; and an identification of the proximate and root causes of the significant claims. A hierarchy of such claims, proximate and root causes is presented, based mainly on data collected from 61 projects and on 46 responses to questionnaires in Hong Kong. Measures of the relative significance of the claims categories are also presented. The results are reinforced by observations from parallel studies in Hong Kong and elsewhere, as well as from the literature. Strategies are suggested to avoid the avoidable and mitigate the unavoidable or unavoided claims, through controlling the controllable causes. Management focus is also recommended on controlling the causes of those categories of claims and disputes that are seen to be significant in terms of higher impact and/or probability of occurrence.
An analysis of causes of disputes in the construction industry using analytical hierarchy process (AHP). AEI 2013 Architectural Engineering Institute Conference, 3-5 April, The Pennsylvania State University The Analytical Hierarchy Process
  • P I Cakmak
  • E Cakmak
Cakmak, P.I., & Cakmak, E. (2013). An analysis of causes of disputes in the construction industry using analytical hierarchy process (AHP). AEI 2013 Architectural Engineering Institute Conference, 3-5 April, The Pennsylvania State University, University Park, Pennsylvania, USA. Saaty, T.L. (1980). The Analytical Hierarchy Process. McGraw-Hill, New York.